A government contractor, pursuant to a fixed-priced contract with the U.S. Department of State, was constructing a rainwater capture and storage facility in Sierra Leone when the Ebola epidemic occurred in 2014. As a result, the contractor suspended its work, demobilized, sent its employees home, and put its construction materials into storage. When it later remobilized, the contractor paid for medical facilities and services onsite for the health and safety of its workforce. When it submitted a Request for Equitable Adjustment (“REA” or “change order”), the government granted a time extension but denied the request for $1.25 million for additional costs incurred. The Civilian Board of Contract Appeals affirmed this decision. Pernix Serka Joint Venture v. Department of State (20-1 BCA P 37589). The key holding was that the Delay clause in the contract specifically disallowed equitable compensation adjustment for an excusable delay based on epidemics.
The contract clause in question provides as follows:
“F.8.1 The Contractor will be allowed time, not money, for excusable delays as defined in FAR 52.249-10, Default (see Section/Paragraph I.153). Examples of such cases include (1) acts of God or of the public enemy; (2) acts of the United States Government in either its sovereign or contractual capacity; (3) acts of the government of the host country in its sovereign capacity; (4) acts of another contractor in the performance of a contract with the Government; (5) fires; (6) floods; (7) epidemics; (8) quarantine restrictions; (9) strikes; (10) freight embargoes; and (11) unusually severe weather.
F.8.2 In each instance, the failure to perform must be beyond the contract and without the fault or negligence of the Contractor, and the failure to perform furthermore (1) must be one that the Contractor could not have reasonably anticipated and taken adequate measures to protect against, (2) cannot be overcome by reasonable efforts to reschedule the work, and (3) directly and materially affects the date of final completion of the project.”
In this case, the contractor was concerned its personnel wouldn’t be safe with the Ebola virus spreading throughout the area, and that it wouldn’t be able to support its personnel if they needed to be evacuated. In seeking guidance from the contracting officer for “instructions on the way forward,” the contractor sought to avoid making a unilateral decision on what to do, but to instead obtain government direction and consensus on what action to take.
The Department of State declined to provide any direction or guidance as to whether the contractor should leave the jobsite. The contractor, feeling strongly that it couldn’t continue to have its personnel work under these conditions, decided to demobilize and shut down the project. It sent notice to the contracting officer of delay related to the crisis. The contractor then directed that all personnel be evacuated from the country.
In response to the notice letter, the contracting officer responded as follows:
“We are aware and acknowledge your concerns in your letter dated 08AUG2014 about the impact the Ebola Outbreak has towards continuing work on this project. Since you are taking this action unilaterally based on circumstances beyond the control of either contracting party, we perceive no basis upon which you could properly claim an equitable adjustment from the Government with respect to additional costs you may incur in connection with your decision to curtail work on this project.”
It is important to note that the contractor made a concerted effort to have the Government Issue direction to suspend the work rather than making a unilateral decision. When the Government refused to act, and the contractor decided on its own what to do, it complained to the contracting officer,
“We felt we were cornered to make a unilateral decision to save our people’s lives essentially, and it felt like it was a chicken game with the Government. They waited us out until we had to leave, and then immediately you get a response that says this is unilateral.”
In addition to the costs of evacuating its employees, the contractor incurred numerous costs, including the costs for temporary power and lighting at the construction site and it hired local security to maintain the generator. In response to the contractor’s REA seeking to recover additional costs, the contracting officer responded,
“PSJV [Contractor] may be entitled to a non-compensable time extension under the excusable delay clause if it can prove that performance of the contract was impossible …. If the [U.S. Government] agrees to the existence of excusable delay conditions, PSJV would be entitled to a time extension only, and not an equitable adjustment for delay costs or the other types of expenses included in PSJV’s [cost proposal].”
Ultimately, the government granted the contractor a time extension for 195 additional calendar days for the Ebola outbreak, but denied any additional compensation. Appeal from this decision was denied by the Board for the reasons set forth below.
Contractor Assumes the Risk in a Firm Fixed-Price Contract
The Board cites several case precedents for the proposition that, “it is well-established that a contractor with a fixed price contract assumes the risk of unexpected costs not attributable to the Government.”
“PSJV’s firm, fixed-price contract obligated PSJV to perform and receive only the fixed price. The contract, in clause F.8.1 and the referenced FAR clause 52.249-10, explicitly addresses how acts of God, epidemics, and quarantine restrictions are to be treated. A contractor is entitled to additional time but not additional costs. Appellant’s attempts to shift the risks clearly articulated by the contact are unavailing.
Particularly given the Excusable Delays clause, PSJV has not identified any clause in the contract that served to shift the risk to the Government for any costs incurred due to an unforeseen epidemic. Nor does the contract require the Government to provide PSJV with direction on how to respond to the Ebola outbreak. Thus, under a firm, fixed-price contract, PSJV must bear the additional costs of contract performance, even if PSJV did not contemplate those measures at the time it submitted its proposal or at contract award.”
No Cardinal Change to the contract
The contractor claimed it “was forced to perform in cardinal change conditions,” or “was constructively ordered to provide medical and life safety measures outside the scope of the contract,” or “incurred costs due to the breach of the government’s implied duty to cooperate.”
A cardinal change, as explained by the Board, is a breach of contract that occurs if the government effects a change in the contractor’s work “so drastic that it effectively requires the contractor to perform duties materially different from those found in the original contract.” In this case, the Board held that the contractor failed to establish a cardinal change and that,
“Despite the difficulties encountered during the Ebola outbreak, the Government never changed the description of work it expected from the contractor. Throughout communications with PSJV, the Government repeatedly stated that it would not give directions to the contractor on how it should respond to the ongoing outbreak, instead leaving the decisions solely in the hands of the contractor. Any changes in conditions surrounding performance of the contract arose from the Ebola outbreak and the host country’s reaction to the outbreak. This situation forced PSJV to reevaluate how it wished to proceed with the work outlined in the contract. Throughout the situation, DOS informed PSJV, on multiple occasions, that it would not order PSJV to evacuate the site and that PSJV must make its own business choices as to whether it needed to demobilize from the site.”
No Constructive Change
The contractor argued that the demobilization and remobilization of its personnel, and the additional site safety measures necessitated by the Ebola outbreak constitute constructive changes by the Government, entitling the contractor to an equitable adjustment for its increased costs. A constructive change occurs where a contractor performs work beyond the contract without a formal order either because of an informal order of the government or due to the fault of the government. To recover on a constructive change argument, a contractor must demonstrate that it performed work beyond the contract requirements — either expressly or implicitly at the direction of the government. Unless an “alteration in the word to be performed” results from government action, there can be no finding of a construction change says the Board. Here, the Board states:
“PSJV acknowledges that DOS did not give it directions or orders to evacuate the project site. In effect, while PSJV concedes that the Government had no contractual obligation to provide direction, it continues to assert that the Government should have done so nonetheless. Simply put, PSJV fails to demonstrate a constructive change because no change to the contract occurred. PSJV remained obligated to perform throughout the performance period, and the Excusable Delay clause provided for additional time, but not additional money.”
For these reasons the Board denied the contractor’s appeal and thereby affirmed the decision of the government to deny equitable adjustment to cover the contractor’s additional costs.
About the author: Article written by J. Kent Holland, Jr., a construction lawyer located in Tysons Corner, Virginia, with a national practice (formerly with Wickwire Gavin, P.C. and now with ConstructionRisk Counsel, PLLC) representing design professionals, contractors and project owners. He is founder and president of a consulting firm, ConstructionRisk, LLC, providing consulting services to owners, design professionals, contractors and attorneys on construction projects. He is publisher of ConstructionRisk Report and may be reached at Kent@ConstructionRisk.com or by calling 703-623-1932. This article is published in ConstructionRisk Report, Vol. 22, No. 8 (Oct/Nov 2020).
Copyright 2020, ConstructionRisk, LLC