by Kent Holland | Mar 15, 2024 | Newsletter Article
Subcontractor had a lump sum multimillion dollar contract. A “no damages for delay” in the contract stated that the Subcontractor recognized the potential for its Work to be delayed by others and would not be compensated for any costs caused by such delay unless the...
by Kent Holland | Feb 20, 2017 | Newsletter Article
Subcontractor filed a complaint for delay damages allegedly caused by the project owner and construction manager’s inept administration and poor administration. Defendants’ motion for summary judgment was granted, and this was affirmed on appeal, on the basis that the...
by Kent Holland | Feb 23, 2015 | Newsletter Article
By: Stanley P. Santire, Esq. Santire Law Firm, Houston, Texas (http://www.santirelaw.com) A “No Damages for Delay” contract provision was found unenforceable, based on the application of public policy principles that had previously only been applied in cases of tort...
by Kent Holland | Apr 26, 2012 | Newsletter Article
A no-damages-for-delay clause was held to prevent a contractor from recovering damages for delays even where there was evidence that poor planning and administration by the project owner contributed to delay and there was evidence that work by other contractors...
Connect