Court Has No Jurisdiction Over a Contractor Claim that Was Based on an Issue Raised to the Contracting Officer for Final Determination but Not Sufficiently Detailed and Explained; Notice Provisions Enforced Against Contractor, and Liquidated Damages Held to be Enforceable

by | Jul 13, 2015 | Newsletter Article

By: Gail S. Kelley, P.E., J.D. ConstructionRisk, LLC Where a contractor amended its complaint in an action against the United States to include a claim for remission of liquidated damages on the basis that it was entitled to a time extension, but the contractor did...