by Kent Holland | Mar 26, 2019 | Newsletter Article
Subcontractor was 95 percent complete with its work when the general contractor (GC) made changes to the scope of work, failed to timely respond to change order requests, and failed to make payment of amounts then due under the subcontract. Without providing...
by Kent Holland | Apr 25, 2016 | Newsletter Article
Gail S. Kelley, J.D., P.E. ConstructionRisk, LLC The plaintiff in this case, Barr Incorporated, was the general contractor (GC) on a project in Berlin, Massachusetts. After being terminated from the project based on a certification from the Architect, the GC sued the...
by Kent Holland | Jul 13, 2011 | Newsletter Article
Demolition delays by others for whom the subcontractor was not responsible significantly impeded the subcontractor’s ability to timely perform its work. Stored equipment and activity of other subcontractors prevented the subcontractor from accessing work areas. And...
by Kent Holland | Feb 9, 2011 | Newsletter Article
By: Robert J. MacPherson, Esq. Surety bonds are contracts and the rights and obligations of the parties will be determined in accordance with basic principles of contract law. The size of the claims and complexity of the project will not impact the result. That is...
Connect